278932 WM17E - C�TV CLERK ��unCl� 2'789'��
PINK - FINANCE G I TY O F S�I NT PA U L � �
CANARY - DEPARTMENT
BLUE - MAVOR File NO.
l�esolution
Presented By
Referred To i Committee: Date
Out of Committee By � Date
-
BE IT RESOLVED, That the Cou�cil of the City of Saint Paul
hereby certifies and approves the action of the City of Saint Paul
Board of Appeals and Review perta ning to the follo�uing listed
property and as shown by the Exce pted Minutes of said Board of
Appeals and Review, dated June 8, I1982, and marked EXHIBIT A, and
attached hereto and made a part h�reof by reference:
DATE OF BOARD
MINUTES CASE NO. PROPER Y APPELLANT
6/8/�2 21-82-H 332 N. ILexington L & M Partnership
(ll unl�ts} By Michael Kiteck
BOARD ACTION: Granted time extenision to October 15, 1982 , to com-
plete installation, of combination windows, �ith
exception of certa�in small, high windows, where a
variance is granteld on St. Paul Legislative Code,
Section 34 . 09, per�taining to screening, to permit
installation of p�'rmanent glazed storm windows.
Property Description: Buel and �ackubin Out Lots
N. 50 Ft. �of W. 113 Ft. of Part S. of
Rondo Ave.l and E. of Lexington Parkway
of Lots 9 I and 10
---------------------------
COU[VCILMEN I
Yeas Nays Requested by Department of:
Fletcher �
�evine [n Favor
Masanz
Nicosia
scheibel � __ Against BY
Tedesco
Wilson
.�UL 6 ��8� I Form Approved by City Attorney
Adopted by Council: Date
Certified a �e by Counci ecre I 7�� ��
sy
Ap v by Mavor: —
JUL I Approved by Mayor for Submission to Council
_ —J BY
PU$LiSH�D ,}UL 17 �98�-
� . �x �' i e i 1� i4 �'��9��
• - - 6/8/82 - Meeting No. 185
. � .
�
.
,
, '
21- 82-H 332 N. Lexi�gton Michael Kiteck
(11 units) for L F A7 Partnership
SUBJECT:
Request time extension to complete re' airs , as designated in city' s letter
of 4/27/82 , because of high cost of s me items (in particular, stairwell
enclasures) , and the delay on the par of the vendor in delivery of com-
bination windows , which are on. order ; remaining items will be completed
within 60 days .
APPEAR.ANCE : Michael Kiteck a
PROCEEDINGS : Mr. Kiteck said he had o objections to any of the work
or-3ers, only to the time allowed. for �ompletion. Aftei- buying the prop-
erty 2% years ago, the partnership ha¢i put in about $18 ,000 for repairs .
The city' s letter of 4/2�/82 granted wo months to comply with deficiencies
that will cost about $8 ,000 to $10 ,00 . Combination windows were to be ,
or already have been, installed on al� windows except for a few, very
small, high windows . On these latter he wanted to pu� on permanent ,
glazed storm windows to make them ene�gy efficient. Every room would
have other windows with combinations �o provide ventilation.
BOARD ACTION: Mr. Tilton moved to gr nt time extension to October 15 ,
1 2 , to complete installation of com}�ination windows , with the exceptian
of certain small high windows , where �. variance is granted to permit
installation of some type of permanen exterior glazed window other than
combinations . Mrs . Collins seconded. � MOTION CARRTED AND SO ORDERED.
THE VOTE: Ayes - 6 Nays - 0 Abstentions - 0
In regard to stairwell enclosures , Mr� Kiteck stated that the city inspector
told him it was impossible to place p rtitions and smoke doors in the
usual manner, but proposed an alterna ive method that was acceptable.
Mr. Kiteck wanted t�ie inspector' s fin�ings on record, since he himself
was not sure that the alternative would meet code.
Don Wagn,er , city inspector whose s�eci�al � field is fire senaration measures ,
assui-ed i�Ir. Kiteck that the method described ivould meet code.
I
.
i .
. 6;�8/8l - Meeting No. 185
' .
b2INUTES OFIITHE MEETING
- ST. PAUL BOARD OFIIAPPEALS � REVIFSU .
1
Tuesday, J�ne 8, 1982
Room 707 City Hall ,l 15 W. Kellogg Blvd�
MEMBERS PRESENT : Ron Glassman , Chlairman
Lucille Collins I
Glenn Gausman
Harold Knutson
William Tilton
Rudolph Sawyer
ABSENT: Rosann Bostrom
AGENCIES PRESENT: Dept. of Communi�y Services - Division of Housing
� Building CodeiEnforcement :
Sarr� Blue I Glenn Erickson Joan Barry
Jerry Kern I Don Wagner Barb Franklin
St. Paul Divisior� of Public Health:
Don Miller I
OTHERS PRESENT: Richard L. Smithll Phyllis M. Smith
Allan Cederberg Lester H. Bruning
R. Cortright Bev Masterman
Shelvin Kie�fer l Michael Kiteck
Charles Wendle Fred Kueppers , Jr.
David Ries Craig 0'Brien
Joel Determan Marvin Masterman
STAFF PRESENT: Patricia Moxness �I .
Chairman Glassman called the meeting �o order at 1 : 30 p.m.
The minutes of the meeting of May 11 , 11982 , were anproved as distributed
to the members . ,
Chairman Glassman reported that two c�ses on the agenda had been settled
admini.stratavely and had been zaithdra�rn. They were Case No. 18- 82-H,
1702 Hague , Appellant Robert Wetterbe�g, and Case No. 23- 82-H, 2129 Grand
Ave . , Appellants Richard L. F PhyllislM. Smith.
CASE N0. PROPERTY I APPELLANT
15- 82-Ii 739- 741 Simsl Ave . Carl E. IVarner
(four units)I
.
.. .... . _ _ I